Monday, April 22, 2024
49.0°F

Legals for March, 19 2024

| March 19, 2024 12:00 AM

NOTICE INVITING BIDS Bid 2024-01 OWNER: Kootenai County Board of County Commissioners (BOCC) 451 Government Way PO Box 9000 Coeur d’Alene, Idaho 83816 Separate sealed BIDS for the construction of: Extend Taxiway C and Relocate MALSR Threshold Lights Coeur d’Alene Airport, Hayden, Idaho FAA/AIP 3-16-0010-061-2024 will be received by the Owner at the Office of the BOCC, 451 Government Way 3rd floor, Coeur d’Alene, Idaho 83814 until 2:00 p.m., Tuesday, April 2, 2024 and then at said location and time, publicly opened and read aloud at Kootenai County Commissioners Meeting on 1st floor. Work associated with proposed improvements is generally described as follows: Bid Schedule A: Taxiway C, Road & Electrical Bid Schedule B: MALSR  Bid Schedule C: Lights and Signs Bid Schedule D: Service Road Bid Schedule E: Taxiway D Demolition  Bid Schedule F: ARFF Road Work generally consists of the new construction of Taxiway C extension, the installation of new MALSR threshold lights, pavement demolition, new road construction, medium intensity taxiway edge lights, guidance signage modifications, preloading, grading and drainage modifications, site restoration, topsoiling, mulched seeding, and other miscellaneous items. Bid Documents will be made available after 3:00 p.m., Friday, March 15, 2024. Digital bidding documents are available at Ardurra - Projects (questcdn.com), reference Quest Number 8974964. Interested parties may view the bidding documents at no cost. Bidders must register with QuestCDN.com at a non-refundable cost of $22.00 to download the bidding documents and be placed on the planholders list. Contact QuestCDN Client Success at 952-233-1632 or Success@QuestCDN.com for assistance in membership registration and downloading digital bidding documents. A Prebid Conference will be held at 10:00 a.m., Thursday, March 21, 2024 at the Airport Manager’s Office, 10375 Sensor Ave, Hayden, Idaho 83835. Attendance is highly recommended, not mandatory.  A Bid Guaranty, payable in cash, by cashiers check, certified check or bid bond, of 5 percent of the BID AMOUNT is required. Separate Performance and Payment Bonds each in the amount of 100 percent of the CONTRACT AMOUNT will be required. Each bidder must supply all the information required by the Bid Documents and Specifications. Kootenai County, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 U.S.C. §§ 2000d to 2000d-4) and the Regulations, hereby notifies all bidders that it will affirmatively ensure that any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, national origin (including limited English proficiency), creed, sex (including sexual orientation or gender identity), age, or disability in consideration for an award. Prospective Contractors are notified that the work under this Contract is funded in part by a grant from the Federal Aviation Administration and as such this solicitation and any resulting contract are subject to the requirements of the Buy America Preference; Civil Rights – Title VI Assurance; Davis Bacon; Debarment and Suspension; Disadvantage Business Enterprise; Foreign Trade Restriction; Lobby Federal Employee; and Recovered Materials contract provisions. By submitting a bid/proposal under this solicitation, the bidder or offeror certifies that neither it nor its principals are presently debarred or suspended by any Federal department or agency from participation in this transaction. All contracts and subcontracts that result from this solicitation incorporate by reference the provisions of 29 CFR part 201, et seq, the Federal Fair Labor Standards Act (FLSA), with the same force and effect as if given in full text. The FLSA sets minimum wage, overtime pay, recordkeeping, and child labor standards for full and part-time workers. The Contractor has full responsibility to monitor compliance to the referenced statute or regulation. The contractor must address any claims or disputes that arise from this requirement directly with the U.S. Department of Labor – Wage and Hour Division. No contractor, subcontractor, or specialty contractor shall be required to have a current license as a Contractor in the State of Idaho in order to submit a bid or proposal on this project; prior to award and execution of the Contract, the successful bidder shall secure an Idaho Public Works Contractor’s License. Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity: 1. The Offeror’s or Bidder’s attention is called to the “Equal Opportunity Clause” and the “Standard Federal Equal Employment Opportunity Construction Contract Specifications” set forth herein. 2. The goals and timetables for minority and female participation, expressed in percentage terms for the Contractor’s aggregate workforce in each trade on all construction work in the covered area, are as follows: Goals for minority participation for each trade 3.0% Goals for female participation in each trade 6.9% These goals are applicable to all of the Contractor’s construction work (whether or not it is Federal or federally assisted) performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, it shall apply the goals established for such geographical area where the work is actually performed. With regard to this second area, the Contractor also is subject to the goals for both its federally involved and non-federally involved construction. The Contractor’s compliance with the Executive Order and the regulations in 41 CFR Part 60-4 shall be based on its implementation of the Equal Opportunity Clause, specific affirmative action obligations required by the specifications set forth in 41 CFR 60-4.3(a) and its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade, and the Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor or from project to project for the sole purpose of meeting the Contractor’s goals shall be a violation of the contract, the Executive Order and the regulations in 41 CFR Part 60-4. Compliance with the goals will be measured against the total work hours performed. 3. The Contractor shall provide written notification to the Director of the Office of Federal Contract Compliance Programs (OFCCP) within 10 working days of award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the name, address, and telephone number of the subContractor; employer identification number of the subContractor; estimated dollar amount of the subcontract; estimated starting and completion dates of the subcontract; and the geographical area in which the subcontract is to be performed. 4. As used in this notice and in the contract resulting from this solicitation, the “covered area” is the State of Idaho, Kootenai County, and the City of Hayden. All prospective bidders are directed to the Instructions for Bidders for discussion of Bid policies, procedures, and requirements. The Owner reserves the right to reject any and all Bids, waive any and all informalities, negotiate contract terms with the successful Bidder, and disregard all non-conforming, non-responsive, or conditional Bids. The requirements of 49 CFR Part 26, Regulations of the U.S. Department of Transportation, apply to this contract. It is the policy of Kootenai County to practice nondiscrimination based on race, color, sex, or national origin in the award or performance of this contract. The Owner encourages participation by all firms qualifying under this solicitation regardless of business size or ownership. For DOT Assisted Contracts during Federal Fiscal Years, Coeur d’Alene Airport has adopted an overall three-year DBE Goal of 0.60% (0.00% Race Conscious and 0.60% Race Neutral). KOOTENAI COUNTY BOARD OF COMMISSIONERS ATTEST: JENNIFER LOCKE, CLERK /s/Leslie Duncan, Chair /s/Teri Johnston Deputy Clerk Legal#12058 AD#19836 March 12, 19, 2024

NOTICE OF HEARING ON NAME CHANGE Case No. CV28-24-1246 IN THE DISTRICT COURT FOR THE FIRST JUDICIAL DISTRICT FOR THE STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI IN RE: Byron Dean Bowen, A petition to change the name of Byron Dean Bowen, now residing in the City of Rathdrum, State of Idaho, has been filed in the District Court in Kootenai County, Idaho. The name will change to Byron Dean Bradley. The reason for the change in name is: to match my driver’s license and social security number to get a passport.  A hearing on the petition is scheduled for 1:30 o’clock p.m. on 4-8-24 at the Kootenai County Courthouse. Objections may be filed by any person who can show the court a good reason against the name change. Date: 2-21-24 Jennifer Locke CLERK OF THE DISTRICT COURT /s/Calvin Graham Deputy Clerk Legal#12071 AD#19919 Feb. 27, March 5, 12, 19, 2024 _________________________

NOTICE OF HEARING ON NAME CHANGE Case No. CV40-24-83 IN THE DISTRICT COURT FOR THE FIRST JUDICIAL DISTRICT FOR THE STATE OF IDAHO, IN AND FOR THE COUNTY OF SHOSHONE IN RE: Mandelynne Anne Goolsby, A petition to change the name of Mandelynne Anne Goolsby, now residing in the City of Wallace, State of Idaho, has been filed in the District Court in Shoshone County, Idaho. The name will change to Abyss Abyss Abyss. The reason for the change in name is: Resonable Accomidation for disability.  A hearing on the petition is scheduled for 10 o’clock a.m. on April 23, 2024 at the Shoshone County Courthouse. Objections may be filed by any person who can show the court a good reason against the name change. Date: February 21, 2024 CLERK OF THE DISTRICT COURT /s/Karen Harshman Deputy Clerk SHOLegal#4681 AD#19923 Feb. 27, March 5, 12, 19, 2024 _________________________

NOTICE OF SUCCESSOR TRUSTEE’S SALE On May 29, 2024 at 1:00 p.m., Pacific Standard Time, at 1250 W. Ironwood Drive, Suite 301, Coeur d’Alene ID 83814, LISA A. HOLMES, a member of the Idaho State Bar and Successor Trustee to KOOTENAI COUNTY TITLE COMPANY, will sell at public auction, to the highest bidder, for cash, in lawful money of the United States of America, all payable at the time of sale, the following parcel of real property located in the County of Kootenai, State of Idaho, to wit: SEE EXHIBIT “A” ATTACHED HERETO AND BY REFERENCE FULLY INCORPORATED HEREIN. The Successor Trustee has no knowledge of a more particular description of the above-referenced real property, but for purposes of complying with Idaho Code section 60-113, the Successor Trustee is informed that the address of the real property is commonly known as Commonly known as 2332 W Smoke Tree Avenue, Athol ID 83801, Kootenai County Assessor’s Parcel AIN109598. Said public auction sale shall be made without covenant, guarantee, representation or warranty of any kind regarding title, possession, encumbrances or condition. Said public auction shall be conducted to satisfy an obligation secured by, and pursuant to the power of sale conferred in the Deed of Trust executed by CHRISTOPHER A. MARI and LINDA S.MARI, husband and wife, of P.O. Box 539, Athol ID 83801-0539, as Grantor, KOOTENAI TITLE COMPANY, INC., as the Trustee, and PANHANDLE AREA COUNCIL, INC., an Idaho nonprofit corporation, as Beneficiary, dated December 1, 2022, was recorded on December 14, 2022, as Instrument No. 2924128000, records of Kootenai County, State of Idaho. Said DEED OF TRUST covers the below described parcel of real property located in the County of Kootenai, State of Idaho, to wit: SEE EXHIBIT “A” ATTACHED HERETO AND BY REFERENCE FULLY INCORPORATED HEREIN. Commonly known as 2332 W Smoke Tree Avenue, Athol ID 83801, Kootenai County Assessor’s Parcel AIN109598. Notice is hereby given that a breach of the obligation for which the transfer in trust is security has occurred, the nature of such breach is the failure to: 1. Failure to pay all sums of principal and interest when due and owing in full on July 1, 2023. 2. Failure to pay late charges. The late fees obligation is ongoing and continuing until such time as all sums due are paid in full. The principal amount owing as of January 2, 2024 is THIRTY-SEVEN THOUSAND TWO HUNDRED TWENTY-ONE AND 28/100’S ($37,221.28). Accrued interest as of January 2, 2024 is in the amount of TWO THOUSAND ONE HUNDRED SEVENTY-FIVE AND 15/100’S ($2,175.15), unpaid late fees in the amount of SIX HUNDRED DOLLARS ($600.00), and other fees due and owing under the Promissory Note and Deed of Trust terms in the amount of TWO HUNDRED FIFTY-FIVE AND NO/100’S DOLLARS ($255.00), for a total owing as of January 2, 2024 in the amount of FORTY THOUSAND TWO HUNDRED FIFTY-ONE AND 43/100’S DOLLARS ($40,251.43), exclusive of all default fees, delinquent taxes, escrow fees, additional costs advanced to protect security, foreclosure and attorneys and trustee’s fees and any interest or penalties thereon. Said delinquent amount continues to accrue interest, late charges and/or fees, escrow fees and/or charges, foreclosure costs and attorneys fees and outstanding taxes and penalties, if any. All delinquencies are now due in full together with all late charges, advances to protect the security, and fees and costs associated with this foreclosure sale.  THE ABOVE NAMED GRANTOR(S)/TRUSTOR(S) ARE NAMED TO COMPLY WITH IDAHO CODE SECTION 45-1506(4)(a). NO REPRESENTATION IS MADE THAT SAID GRANTOR(S)/TRUSTOR(S) IS(ARE), OR IS(ARE) NOT PRESENTLY RESPONSIBLE FOR THIS OBLIGATION. The Beneficiary elects, and has directed the Successor Trustee, to sell or cause the aforementioned parcel of real property to be sold to satisfy said obligations. The sale shall be governed by the provisions contained in Title 45, Chapter 15, Idaho Code. The Successor Trustee’s authority herein is evidenced by an appointment of successor Trustee recorded as Instrument No. 2958289000 in the records of Kootenai County, State of Idaho. Pursuant to Idaho Code Section 45-1506(12): “Whenever all or a portion of any obligation secured by a deed of trust which has become due by reason of a default of any part of that obligation, including taxes, assessments, premiums for insurance or advances made by a beneficiary in accordance with the terms of the deed of trust, the grantor or his successor in interest in the trust property or any part thereof, or any beneficiary under a subordinate deed of trust or any person having a subordinate lien or encumbrance of record thereon, at any time within one hundred fifteen (115) days of the recording of the notice of default under such deed of trust, if the power of sale therein is to be exercised, or otherwise at any time prior to the entry of a decree of foreclosure, may pay to the beneficiary or their successors in interest, respectively, the entire amount then due under the terms of the deed of trust and the obligation secured thereby (including costs and expenses actually incurred in enforcing the terms of such obligation and a reasonable trustee’s fee subject to the limitations imposed by subsection (6) of section 45-1502, Idaho Code, and attorney’s fees as may be provided in the promissory note) other than such portion of the principal as would not then be due had no default occurred, and thereby cure the default theretofore existing, and thereupon, all proceedings theretofore had or instituted shall be dismissed or discontinued and the obligation and deed of trust shall be reinstated and shall be and remain in force and effect, the same as if no acceleration had occurred.” Pursuant to Idaho Code Section 45-1505(3): “Mortgage foreclosure is a legal proceeding where a lender terminates a borrower’s interest in property to satisfy unpaid debt secured by the property. This can mean that when a homeowner gets behind on his or her mortgage payments, the lender forces a sale of the home on which the mortgage loan is based. Some individuals or businesses may say they can “save” your home from foreclosure. You should be cautious about such claims. It is important that you understand all the terms of a plan to “rescue” you from mortgage foreclosure and how it will affect you. It may result in your losing valuable equity that you may have in your home. If possible, you should consult with an attorney or financial professional to find out what other options you may have. Do not delay seeking advice, because the longer you wait, the fewer options you may have. Under Idaho law, you have five (5) days to rescind or undo certain contracts or agreements that relate to transferring interests in property or money in a foreclosure situation. An attorney or financial professional can tell you more about this option.” THIS NOTICE IS AN ATTEMPT TO COLLECT A DEBT AND ANY INFORMATION OBTAINED AS A RESULT HEREOF WILL BE USED FOR THAT PURPOSE. Dated this January 22, 2024. /S/LISA A. HOLMES, Successor Trustee To TITLE ONE LISA A. HOLMES, ISB 4525 HOLMES LAW OFFICE, P.A. 1250 W. IRONWOOD DRIVE SUITE 301 COEUR D’ALENE ID 83814 TELEPHONE (208)664-2351 FACSIMILE (208)664-2323 EXHIBIT “A” THE SOUTHWEST QUARTER OF THE NORTHWEST QUARTER OF THE SOUTHEAST QUARTION OF SECTION 15, TOWNSHIP 53 NORTH, RANGE 4 WEST BOISE MERIDIAN, KOOTENAI COUNTY, IDAHO. Legal#12074 AD#19934 February 27, March 5, 12, 19, 2024 _________________________

SUMMONS re: KAVESHAN EXCAVATING, LLC Case No. CV28-23-5550 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO IN AND FOR THE COUNTY OF KOOTENAI MICHAEL EISELE, a married man and KRISTINE EISELE, a married woman, and the marital community composed thereof, Plaintiff, vs. KLEINSMITH CUSTOM HOMES, LLC, an Idaho limited liability company, Defendant/Third-Party Plaintiff. ________________________ KLEINSMITH CUSTOM HOMES, LLC, an Idaho limited liability company, Third-Party Plaintiff vs. RICHARD H. COOKE, individually and/or d/b/a RAZ FRAMING; NICHOLAS COLLING, individually, and/or d/b/a and/or a/k/a CN EXTERIORS; MODERN GLASS COMPANY, INC.; PATRICK ADAMS, individually, and/or d/b/a ADAMS TRIM WORKS; ADAMS TRIM WORKS, LLC; BRENT KAUFMAN, individually, and/or d/b/a T.K.’S PAINTING; T.K.’S PAINTING, LLC; MYRON R. FARRAR and LISA A. FARRAR, individually, and/or d/b/a LAKE CITY ROOFING & CONSTRUCTION; LAKE CITY POWER WASH & ROOFING, INC.; GATOR WATERPROOFING SERVICES, LLC; DANIEL W. KAVESHAN, individually, and/or d/b/a KAVESHAN EXCAVATING; KAVESHAN EXCAVATING, LLC; QUARRY PEACOCK, individually, and/or d/b/a ARC INTERIORS; QUARRY’S CONSTRUCTION, LLC, d/b/a ARC INTERIORS; SCOTT BENNETT and SHANNON BENNETT, individually, and/or d/b/a, BENNETT CONCRETE; JON W. ARABIAN, individually, and/or d/b/a ARABIAN CONSTRUCTION; HUGHES MASONRY, LLC; and DOES 1-5,         Third-Party Defendants. NOTICE: YOU HAVE BEEN SUED BY THE ABOVE-NAMED DEFENDANT/THIRD-PARTY PLAINTIFF. THE COURT MAY ENTER JUDGMENT AGAINST YOU WITHOUT FURTHER NOTICE UNLESS YOU RESPOND WITHIN 21 DAYS. READ THE INFORMATION BELOW. TO: Kaveshan Excavating, LLC You are hereby notified that in order to defend this lawsuit, an appropriate written response must be filed with the above-designated court at 324 West Garden Avenue, Coeur d’Alene, Idaho 83814 within 21 days after service of this Summons on you. If you fail to respond, the Court may enter a Judgment against you as demanded by the Defendant/Third-Party Plaintiff in the Third-Party Complaint. A copy of the following is served with this Summons:   1. Verified Complaint; 2. Answer to Complaint, Third-Party Complaint, and Demand for Jury Trial. If you wish to seek the advice or representation by an attorney in this matter, you should do so promptly so that your written response, if any, may be filed in time and other legal rights protected.   An appropriate written response requires compliance with Rule 2, and other Idaho Rules of Civil Procedure, and shall also include: 1. The title and number of this case; 2. If your response is an Answer to the Third-Party Complaint, it must contain admissions or denials of the separate allegations contained in the Third-Party Complaint and other defenses you may claim; 3. Your signature, mailing address and telephone number, or the signature, mailing address and telephone number of your attorney; 4. Proof of mailing or delivery of a copy of your response to Defendant/Third-Party Plaintiff’s attorney, as designated above.  To determine whether you must pay a filing fee with your response, contact the Clerk of the above-named Court, (208) 446-1170.  DATED: 11/7/2023. JENNIFER LOCKE,  CLERK OF THE DISTRICT COURT By/s/Mary Seevers DEPUTY CLERK Michael P. Stefanic, ISB No. 4029 Matthew R. Comstock, ISB No. 10245 ANDERSON, JULIAN & HULL LLP C. W. Moore Plaza 250 South Fifth Street, Suite 700 P. O. Box 7426 Boise, ID 83707-7426 Telephone: (208) 344-5800 Facsimile: (208) 344-5510 E-mail: service@ajhlaw.com Attorneys for Defendant/Third-Party Plaintiff  Kleinsmith Custom Homes, LLC Legal#12075 AD#19938 March 12, 19, 26, April 2, 2024 _________________________

SUMMONS re: DANIEL W. KAVESHAN, Individually, and/or d/b/a KAVESHAN EXCAVATING Case No. CV28-23-5550 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO IN AND FOR THE COUNTY OF KOOTENAI MICHAEL EISELE, a married man and KRISTINE EISELE, a married woman, and the marital community composed thereof, Plaintiff, vs. KLEINSMITH CUSTOM HOMES, LLC, an Idaho limited liability company, Defendant/Third-Party Plaintiff. KLEINSMITH CUSTOM HOMES, LLC, an Idaho limited liability company, Third-Party Plaintiff vs. RICHARD H. COOKE, individually and/or d/b/a RAZ FRAMING; NICHOLAS COLLING, individually, and/or d/b/a and/or a/k/a CN EXTERIORS; MODERN GLASS COMPANY, INC.; PATRICK ADAMS, individually, and/or d/b/a ADAMS TRIM WORKS; ADAMS TRIM WORKS, LLC; BRENT KAUFMAN, individually, and/or d/b/a T.K.’S PAINTING; T.K.’S PAINTING, LLC; MYRON R. FARRAR and LISA A. FARRAR, individually, and/or d/b/a LAKE CITY ROOFING & CONSTRUCTION; LAKE CITY POWER WASH & ROOFING, INC.; GATOR WATERPROOFING SERVICES, LLC; DANIEL W. KAVESHAN, individually, and/or d/b/a KAVESHAN EXCAVATING; KAVESHAN EXCAVATING, LLC; QUARRY PEACOCK, individually, and/or d/b/a ARC INTERIORS; QUARRY’S CONSTRUCTION, LLC, d/b/a ARC INTERIORS; SCOTT BENNETT and SHANNON BENNETT, individually, and/or d/b/a, BENNETT CONCRETE; JON W. ARABIAN, individually, and/or d/b/a ARABIAN CONSTRUCTION; HUGHES MASONRY, LLC; and DOES 1-5,         Third-Party Defendants. NOTICE: YOU HAVE BEEN SUED BY THE ABOVE-NAMED DEFENDANT/THIRD-PARTY PLAINTIFF. THE COURT MAY ENTER JUDGMENT AGAINST YOU WITHOUT FURTHER NOTICE UNLESS YOU RESPOND WITHIN 21 DAYS. READ THE INFORMATION BELOW. TO: Daniel W. Kaveshan, Individually, and/or d/b/a Kaveshan Excavating You are hereby notified that in order to defend this lawsuit, an appropriate written response must be filed with the above-designated court at 324 West Garden Avenue, Coeur d’Alene, Idaho 83814 within 21 days after service of this Summons on you. If you fail to respond, the Court may enter a Judgment against you as demanded by the Defendant/Third-Party Plaintiff in the Third-Party Complaint. A copy of the following is served with this Summons:   1. Verified Complaint; 2. Answer to Complaint, Third-Party Complaint, and Demand for Jury Trial. If you wish to seek the advice or representation by an attorney in this matter, you should do so promptly so that your written response, if any, may be filed in time and other legal rights protected.   An appropriate written response requires compliance with Rule 2, and other Idaho Rules of Civil Procedure, and shall also include: 1. The title and number of this case; 2. If your response is an Answer to the Third-Party Complaint, it must contain admissions or denials of the separate allegations contained in the Third-Party Complaint and other defenses you may claim; 3. Your signature, mailing address and telephone number, or the signature, mailing address and telephone number of your attorney; 4. Proof of mailing or delivery of a copy of your response to Defendant/Third-Party Plaintiff’s attorney, as designated above.  To determine whether you must pay a filing fee with your response, contact the Clerk of the above-named Court, (208) 446-1170.   DATED: 11/7/2023. JENNIFER LOCKE,  CLERK OF THE DISTRICT COURT By/s/Mary Seevers DEPUTY CLERK Michael P. Stefanic, ISB No. 4029 Matthew R. Comstock, ISB No. 10245 ANDERSON, JULIAN & HULL LLP C. W. Moore Plaza 250 South Fifth Street, Suite 700 P. O. Box 7426 Boise, ID 83707-7426 Telephone: (208) 344-5800 Facsimile: (208) 344-5510 E-mail: service@ajhlaw.com Attorneys for Defendant/Third-Party Plaintiff  Kleinsmith Custom Homes, LLC Legal#12076 AD#19939 March 12, 19, 26, April 2, 2024 _________________________

NOTICE OF TRUSTEE’S SALE On the 25th day of June, 2024, at the hour of 10:00 a.m. of this day (recognized local time), in the office of TitleOne, 2065 W. Riverstone Dr., Suite 300, Coeur d’Alene, ID 83814, in the County of Kootenai, State of Idaho, Secured Land Transfers LLC, a Delaware limited liability company dba TitleOne, as Successor Trustee, will sell at public auction to the highest bidder, for cash or cashier’s check (cash equivalent), in lawful money of the United States, all payable at the time of sale in compliance with Section 45-1506(9) Idaho Code, the following described real property, situated in Kootenai County, State of Idaho, and described as follows to wit: Lot 22 in Block 4 of Black Rock, according to the plat filed in Book I of Plats at Page(s) 299, records of Kootenai County, Idaho.   The Trustee has no knowledge of a more particular description of the above referenced real property, but for purposes of compliance with Section 60-113, Idaho Code, the Trustee has been informed that according to the County Assessor’s office, the address of Lot 151 South Basalt Drive, Coeur D Alene, ID 83814, is sometimes associated with said real property. Said sale will be made without covenant or warranty regarding title, possession, or encumbrances to satisfy the obligation secured by and pursuant to the power of sale conferred in the Deed of Trust executed by McCraken Excavation & Underground, Inc., a corporation, also shown of record as McCracken Excavation & Underground, Inc., a corporation, as Grantor(s), Secured Land Transfers LLC, a Delaware limited liability company dba TitleOne, as Successor Trustee, and Varela Equity Management LLC, a Washington limited liability company, as Beneficiary, recorded February 16, 2023, as Instrument No. 2928912000, in the records of Kootenai County, Idaho. THE ABOVE GRANTORS ARE NAMED TO COMPLY WITH SECTION (45-1506)(4)(A), IDAHO CODE. NO REPRESENTATION IS MADE THAT THEY ARE, OR ARE NOT, PRESENTLY RESPONSIBLE FOR THIS OBLIGATION. The beneficiary hereby gives notice that a breach of obligation for which said transfer in security has occurred, the nature of the breach being: a) The default for which this sale is to be made is the failure to pay when due, under Deed of Trust Note, the entire loan balance immediately due and payable in the amount of $95,000.00, for Principal, due and payable on or before February 15, 2024, with unpaid accrued interest owing in the amount of $3,359.85, as of September 15, 2023. With default interest rate of an additional 7.5%.   b) The default for which this sale is to be made is the failure to pay past due real property taxes in Kootenai County for the first half of 2023, and failure to bring said real property taxes current. All amounts are now due, together with unpaid and accruing taxes, assessments, late fees, trustee’s fees, attorney’s fees, costs and advances made to protect the security associated with this foreclosure and all are accruing until the date of sale, full satisfaction, or reinstatement of the obligation. Therefore, the Beneficiary elects to sell or cause the trust property to be sold to satisfy said obligation. Dated: February 22, 2024 Secured Land Transfers LLC dba TitleOne Successor Trustee By: /s/Sheri Coleman Trust Officer Legal#12118 AD#20152 March 5, 12, 19, 26, 2024 _________________________

AMENDED NOTICE TO CREDITORS Case No. CV28-23-0823 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF KOOTENAI MAGISTRATE DIVISION IN THE MATTER OF THE ESTATE OF: HADLEY JUNE MORT, Deceased. NOTICE IS HEREBY GIVEN that Bryce Daniel Mort has been appointed Administrator of the Estate of Hadley June Mort, deceased. All persons having claims against the decedent, or the estate are required to present their claims within four months after the date of the first publication of this Notice or said claims will be forever barred.   Claims must be filed with the Clerk of the Court and presented to the undersigned attorney for the Personal Representative at the following address: 420 N. 2nd Ave., Ste. 112, Sandpoint ID 83864. DATED this 29th day of February, 2023. DUNBAR LAW PLLC /s/ Alison M. Dunbar Attorneys for Applicant Legal# 12126 AD# 20212 March 5,12,19, 2024 _________________________

NOTICE OF LETTING All sealed proposals must be received by 2:00 P.M. MDT, on March 27, 2024, for the purchase of traffic control devices in the City of Osburn, City of Kellogg, Twin Falls Highway District, City of Twin Falls, City of Rexburg, Jefferson County, and the City of Ashton, all in Idaho; Key No. 22871. Sealed bids will be opened at 3:00 P.M. MDT on March 27, 2024, at LHTAC, 3330 Grace St, Boise ID 83703. This project IS Federally Funded All questions must be submitted in writing (email), no later than March 20, 2024 at 5:00 P.M. MDT. Submit questions to: Mike Cram, Administrative Manager Email: MCram@LHTAC.org For clarification of bidding requirements, contact Mike Cram at {208) 344-0565. *********All Bidders must contact LHTAC at (208) 344-0565 and speak with Kellie McKinney or Mike Cram to be placed on the Registered Bidders List. ONLY BIDDERS ON THE REGISTRATION LIST WILL BE CONSIDERED AT BID OPENING.********* Digital copies of the plans, proposals and specifications can be downloaded from QuestCDN.com. Please contact QuestCDN at {952) 233-1632 or info@questcdninfo.com for assistance. Additionally, plans, specifications, proposal forms, and other information may be obtained, and are on file for examination at IDAHO AGC, 1649 WEST SHORELINE DR. SUITE 100, BOISE IDAHO 83702, are also available electronically at the IDAHO AGC’s plan room website, www.idahoagc.org or the Local Highway Technical Assistance Council website, www.lhtac.org. LHTAC’s QuestCDN number is 8010870 Bids must be returned in a sealed envelope clearly marked and addressed as shown below: ATTENTION: LHTAC Bidder: [name of company submitting the bid] Sealed Bid For: Group Sign Project FY22 Bid Number: Key No. 22871 Closes: [Bid closing date] Mailing Address LHTAC 3330 Grace St Boise, ID 83703 SHOLegal#4692 AD#20230 March 12, 19, 2024

NOTICE OF TRUSTEE’S SALE On Wednesday, the 3rd day of July, 2024, at the hour of 10:00 o’clock a.m. of said day at Alliance Title & Escrow, 2157 N. Main Street, Coeur d’Alene, in the County of Kootenai, State of Idaho, Ryan M. Fawcett, as Successor Trustee, will sell at public auction, to the highest bidder, for cash, in lawful money of the United States, all payable at the time of sale, the following described real property situated in the County of Kootenai, State of Idaho, and described as follows, to-wit: Lot 3, Block 2, WINDSONG FIRST ADDITION, according to the plat recorded in the office of the County Recorder in Book “G” Plats at Page 90, records of Kootenai County, Idaho. The Successor Trustee has no knowledge of a more particular description of the above-referenced real property, but for purposes of compliance with Section 60-113, Idaho Code, the Successor Trustee has been informed that the street address of 1206 E. Soft Breeze Ave., Post Falls, Idaho, is sometimes associated with said real property. Said sale will be made without covenant or warranty regarding title, possession or encumbrances to satisfy the obligation secured by and pursuant to the power of sale conferred in the Deed of Trust executed by TRUDI A TUCKER, a Married Woman as her Sole and Separate Property, Grantor, to Ryan M. Fawcett, Successor Trustee, for the benefit and security of IDAHO HOUSING AND FINANCE ASSOCIATION, recorded December 13, 2011, as Instrument No. 2338615000. THE ABOVE GRANTOR IS NAMED TO COMPLY WITH SECTION 45-1506 (4)(a), IDAHO CODE. NO REPRESENTATION IS MADE THAT SHE IS, OR IS NOT, PRESENTLY RESPONSIBLE FOR THIS OBLIGATION. Said sale is a public auction for which the bid price must be paid immediately upon close of bidding by certified funds in the form of cashier’s checks, certified checks, or valid money orders only. If the Trustee is unable to convey title for any reason whatsoever, the successful bidder’s exclusive and sole remedy shall be the return of actual monies paid to the Successor Trustee and the successful bidder shall have no further recourse. The default for which this sale is to be made is the failure to pay when due, monthly installment payments under the Deed of Trust Note dated December 7, 2011, in the amount of $988.00 each, for the months of June, 2023 through January, 2024, inclusive. All delinquent payments are now due, plus accumulated late charges, plus all escrow advances, plus any costs or expenses associated with this foreclosure. The accrued interest is at the rate of 4.10% per annum from May 1, 2023, and the Beneficiary elects to sell or cause the trust property to be sold to satisfy said obligation. The principal balance owing as of this date on the obligation secured by said Deed of Trust is $108,261.29, plus accrued interest at the rate of 4.10% per annum from May 1, 2023. DATED This 4th day of March, 2024. /s/RYAN M. FAWCETT, a Member of the  Idaho State Bar, SUCCESSOR TRUSTEE Legal#12160 AD#20455 March 12, 19, 26, April 2, 2024 _________________________

ADVERTISEMENT - REQUEST FOR STATEMENT OF QUALIFICATIONS The Idaho Department of Fish and Game (IDFG) is soliciting responses to a Request for Qualifications (RFQ) to select one qualified consulting firm (i.e., Consultant) to provide comprehensive consulting, engineering, surveying, and construction oversight services to the Idaho Department of Fish and Game (IDFG). This contract will be for services to generate conceptual designs for aquatic habitat restoration projects on 3.3 miles of the Pahsimeroi River and 1,200’ of Sulphur Creek, a tributary to the Pahsimeroi River, and ready to bid final detailed designs and specifications for one reach/ phase of the larger reach. Anticipated work tasks include site survey, bathymetry, hydraulic modelling, permitting support, and construction oversight. Proposal packets can be obtained from the Fisheries Bureau of the Idaho Department of Fish and Game at 600 S. Walnut Street, Boise, Idaho (contact Matt Belnap, (208-287-2798). Proposals are due at the same address, Attn: Matt Belnap, IDFG, 600 S. Walnut Street, Boise, ID 83707, no later than Friday, May 3, 2024 at 3:00 p.m. local time. All acceptable proposals on a basis consistent with RFQ requirements will be considered.  IDFG reserves the right to reject any and all proposals, to waive any irregularities in the proposals received and to accept the proposal(s) that are in the best interest of the Department.  Questions that arise as a result of this RFQ should be addressed to Matt Belnap, Fisheries Bureau (208-287-2798); all interested parties should contact Matt via e-mail (matt.belnap@idfg.idaho.gov) to ensure inclusion on the distribution list and to receive electronic copies of the RFQ and associated appendices. MATT BELNAP FISH HABITAT PROGRAM COORDINATOR FISHERIES BUREAU IDAHO DEPARTMENT OF FISH AND GAME Legal#12164 AD#20467 March 12, 19, 2024 _________________________

NOTICE  Request for Statements of Qualifications CONSULTING SERVICES The Coeur d’ Alene Airport, as the owner/sponsor of a public-use airport facility, is soliciting Statements of Qualifications for professional airport engineering/architectural services at the Coeur d’ Alene Airport. Airport projects that may be completed under this selection may be funded by FAA AIP funds or other sources. Interested firms are to submit six (6) complete bound copies, one (1) unbound copy and one (1) copy on a flash drive of the Statements of Qualifications to the Board of County Commissioners by 2:00 p.m. April 9, 2024. Submittals should be mailed or delivered to the Board of County Commissioners; P. O. Box 9000, Coeur d’Alene, ID 83816-9000. Late submittals will not be accepted.  A complete copy of the Request for Statements of Qualifications and Experience may be obtained from the Airport Director’s office via email at kstevenson@kcgov.us or via phone at (208) 446-1860.  The Consultant must supply all information required by the Request for Statements of Qualifications and Experience. The Coeur d’Alene Airport reserves the right to waive any informalities and minor irregularities in the submittals and to select the consultant deemed, in the opinion of the Airport, to be in the best interest of Kootenai County and the Airport. All proposals received will be evaluated based on FAA Advisory Circular 150/5100-14E, and on compliance with the request. Projects funded through FAA grants will be subject to the provisions of Executive Order 11246 (Affirmative Action to Ensure Equal Employment Opportunity) and to the provisions of the Department of Transportation Regulations 49 CFR Part 26 (Disadvantaged Business Enterprise Participation) and to foreign trade restrictions. DBE firms are encouraged to apply. For questions regarding this Statement of Qualification, please contact Gaston Patterson, Airport Director, via email at gpatterson@kcgov.us or via phone at (208) 446-1860. KOOTENAI COUNTY BOARD OF COMMISSIONERS ATTEST: JENNIFER LOCKE, CLERK /s/Leslie Duncan, Chairman    By:/s/Teri Johnston, Deputy Clerk Legal#12167 AD#20481 March 12, 19, 2024 _________________________

NOTICE OF PUBLIC HEARING NOTICE IS HEREBY GIVEN that the Kootenai County Hearing Examiner will conduct a public hearing virtually and in Room 1 at or after the hour of 6:00 p.m. on April 18, 2024 to consider CUP22-0020, Brand RV Park, a request by Constance Brand and Brent Ottosen for a Conditional Use Permit to establish a Commercial Resort to operate a Recreational Vehicle (RV) Park on a 36-acre parcel in the Agricultural zone. The subject parcel numbers are 48N05W152000 and 48N05W143700 and described as: SE-NE EX N 132 FT & EX RW and SW-NW EX RW, respectively, all located in Section 14, Township 48 North, Range 05 West, Boise Meridian, Kootenai County, Idaho. The proposed site is located south and adjacent to W. Elder Road approximately 400 feet west of the intersection between Highway 95 and W. Elder Road. All written comments must be received ten (10) days prior to the hearing date. You can submit your comments to kcnoticecomments@kcgov.us. For additional information please contact Kootenai County-Community Development located at 451 Government Way, Coeur d’Alene, ID 83816-9000, (208) 446-1070. Legal#12170 AD#20548 March 19, 2024 _________________________

NOTICE OF PUBLIC HEARING NOTICE IS HEREBY GIVEN that the Kootenai County Hearing Examiner will conduct a public hearing virtually and in Room 1A/B on April 18, 2024 at 6:00 p.m., 451 N. Government Way, Coeur d’Alene, ID to consider Case No. ZON24-0001, Thomas and Beth Osborne to complete a Zone Change from Agriculture to Rural on approximately 10.96 acres of land. The parcel number is 52N04W-33-3250. The parcel is described as: TAX #10326 EX E 841 FT & EX W 60 FT [IN NW-NW] in Section 33, Township 52N, Range 04W B.M. Kootenai County Idaho. The subject site is located at 4882 W. Highway 53. All written comments must be received ten (10) days prior to the hearing date. You can submit your comments to kcnoticecomments@kcgov.us or for addition information please contact Kootenai County-Community Development located at 451 Government Way, Coeur d’Alene, ID 83816-9000, (208) 446-1070. Legal#12171 AD#20552 March 19, 2024 _________________________

NOTICE OF PUBLIC HEARING NOTICE IS HEREBY GIVEN that the Kootenai County Hearing Examiner will conduct a public hearing virtually and in Room 1A/B at or after the hour of 6:00 p.m. on April 18, 2024 to consider CUP23-0010, Camp Swan Lake RV Campground, a request by Dellarese Kennon and Paul Kennon Sr. for a Conditional Use Permit to establish a Commercial Resort to operate a Recreational Vehicle (RV) Park on a 10.816-acre parcel in the Agricultural zone. The subject parcel number is 47N02W060400 and described as: TAX #16612 [IN SW-NE] in Section 6, Township 47 North, Range 02 West, B. M. Kootenai County, ID. The proposed site is located west of the intersection between Highway 3 and E. Black Lake Road and addressed at 35551 S Highway 3, Saint Maries, ID 83861. All written comments must be received ten (10) days prior to the hearing date. For additional information please contact Kootenai County-Community Development located at 451 Government Way, Coeur d’Alene, ID 83816-9000, (208) 446-1070. Legal#12182 AD#20632 March 19, 2024 _________________________